summary
Introduced
03/09/2021
03/09/2021
In Committee
03/17/2021
03/17/2021
Crossed Over
Passed
Dead
01/03/2023
01/03/2023
Introduced Session
117th Congress
Bill Summary
A BILL To require the Director of the Office of Management and Budget to submit to Congress an annual report on projects that are over budget and behind schedule, and for other purposes.
AI Summary
This bill, known as the Billion Dollar Boondoggle Act of 2021, requires the Director of the Office of Management and Budget to submit an annual report to Congress on federal projects that are over budget by at least $1 billion or more than 5 years behind schedule. The report must include details such as the project's purpose, location, contract information, timeline, cost estimates, reasons for delays or cost overruns, and any performance bonuses awarded. The goal is to provide increased transparency and oversight over major government projects that have experienced significant cost and scheduling issues.
Committee Categories
Military Affairs and Security
Sponsors (7)
Joni Ernst (R)*,
Marsha Blackburn (R),
Mike Braun (R),
Maggie Hassan (D),
James Lankford (R),
Gary Peters (D),
Rick Scott (R),
Last Action
Placed on Senate Legislative Calendar under General Orders. Calendar No. 56. (on 05/10/2021)
Official Document
bill text
bill summary
Loading...
bill summary
Loading...
bill summary
Loading...