Legislator
Legislator > Mark Born
State Representative
Mark Born
(R) - Wisconsin
Wisconsin Assembly District 37
In Office - Started: 01/06/2025
contact info
Capitol Office
P.O. Box 8952
State Capitol, 2 E. Main St.
Madison, WI 53708
State Capitol, 2 E. Main St.
Madison, WI 53708
Phone: 608-237-9137
Phone 2: 888-534-0037
Voting Address
135 Franklin St.
Beaver Dam, WI 53916
Beaver Dam, WI 53916
| Bill | Bill Name | Summary | Progress |
|---|---|---|---|
| SB296 | Enumeration of projects in the Authorized State Building Program, modifications to building program project budgets, selection of project architects and engineers, single prime contracting, agency cooperation with energy conservation contractors, timeline for claims before the Claims Board, and making a transfer to the state building trust fund. (FE) | PROJECT ENUMERATIONS OF IN THE AUTHORIZED STATE BUILDING PROGRAM Under current law, the Building Commission may authorize the design and construction of any building, structure, or facility costing in excess of $2,000,000, only if that project is enumerated in the Authorized State Building Program, which appears in each biennial budget passed by the legislature. This bill eliminates that enumeration requirement for the design phase of a project and provides that the LRB-3201/1 MPG/MIM/JPC:skw 2025 - 2026 Legislature SENATE BILL 296 construction of any building, structure, or facility may not be enumerated in the authorized state building program unless the building commission determines that at least 50 percent of the project[s design phase has already been completed. REPORTS CONCERNING MODIFICATIONS TO BUILDING PROGRAM PROJECTS Under current law, the Building Commission has the authority to authorize limited changes in the program or budget of a building program project if the commission determines that unanticipated program conditions or bidding conditions require the change to effectively and economically construct the project. This bill requires that the Department of Administration submit a quarterly report to the Joint Committee on Finance and each voting member of the Building Commission that identifies each project for which the Building Commission has approved a budget increase and that identifies each project enumerated in the state building program for which DOA estimates a budget increase will be necessary for project completion, including a description of the reasons for the project budget shortfall. SELECTION OF PROJECT ARCHITECTS AND ENGINEERS Under current law, the secretary of administration is required to establish a committee for each construction project under DOA[s supervision, except certain emergency projects, for the purpose of selecting an architect or engineer for the project. If the estimated cost of a construction project is $7,400,000 or more, the selection committee must use a request-for-proposal process established by DOA to select an architect or engineer for the project based on qualifications. The bill raises that threshold to $15,000,000. SINGLE PRIME CONTRACTING The bill creates a new exception to single prime contracting for high-dollar building projects. Single prime contracting is a process in which the state contracts only with a general prime contractor who then must contract with subcontractors. Under current law, whenever the Building Commission determines that the use of innovative types of design and construction processes will make better use of the resources and technology available in the building industry, the commission may waive certain requirements related to single prime contracting, if the action is in the best interest of the state and is approved by the commission. Under the bill, for any project costing $200,000,000 or more, at the request of the agency for which the project is constructed, the Building Commission is required to waive certain single prime contracting requirements for the project, as requested by the agency. CERTAIN PROJECT BIDDING PROCEDURES Under the bill, at any time more than two days prior to the end of the period during which bids may be submitted for a building project, a bidder or potential bidder may submit a question to DOA concerning the project. Additionally, the bill provides that DOA may issue addenda at any time during the bidding period to LRB-3201/1 MPG/MIM/JPC:skw 2025 - 2026 Legislature SENATE BILL 296 modify or clarify the drawings and specifications for the project being bid or to extend the bidding period. COOPERATION WITH ENERGY CONSERVATION CONTRACTORS Current law authorizes DOA to contract with qualified contractors for the performance of energy conservation audits at state buildings, structures, and facilities and for the performance of construction work at a state building, structure, or facility for the purpose of realizing potential savings of future energy costs identified in an energy conservation audit. The bill requires DOA and the Board of Regents of the University of Wisconsin System to collaborate with energy service companies to identify and execute pilot projects using financing provided by the companies to upgrade facilities, reduce deferred maintenance, and increase sustainability. UTILITIES COSTS The bill provides that each state contract for construction work must state which party to the contract is responsible for paying project utility service connection charges and which party is responsible for paying for costs related to the consumption of utility services at the project site. ACTIONS AGAINST THE STATE RELATED TO CERTAIN CONTRACT CLAIMS Under current law, the Claims Board is required to receive, investigate, and make recommendations on all claims against the state of $10 or more that are referred to the board by DOA. The board is required to report its findings and recommendations on all claims referred to the board to the legislature. The board may deny a claim, directly pay a claim of up to $10,000, or recommend a payment in excess of $10,000 to the legislature. If the board concludes that a claim should be paid by the state and the board does not or may not directly pay the claim, current law requires the board to cause a bill to be drafted covering its recommendations. A claimant may commence a lawsuit against the state upon the refusal of the legislature to pass a bill allowing a claim. The bill creates a timeline for the board to hear and make a final determination upon certain claims related to contracts and, in addition to current law, allows claimants to bring actions against the state related to certain contract claims if certain conditions are met. Under the bill, any claim referred to the board that relates to a contract with the Department of Transportation for transportation infrastructure improvement or that relates to a contract with DOA or the Board of Regents of the University of Wisconsin System that is awarded under current law for construction projects must be heard by the board, and the board must make a final determination on the claim, within six months from the day that the claim was referred to the board. If the board concludes that the facts of the claim would be more properly adjudicated in a court of law or if the board fails to make a final determination on the claim within six months from the date that the claim was referred to the board, the bill allows the claimant to commence an action against the state seeking judgment on the claim as provided under current law. LRB-3201/1 MPG/MIM/JPC:skw 2025 - 2026 Legislature SENATE BILL 296 TRANSFER TO THE BUILDING TRUST FUND The bill transfers $32,000,000 from the general fund to the building trust fund in fiscal year 2024-25. For further information see the state fiscal estimate, which will be printed as an appendix to this bill. | In Committee |
| AB315 | The Warren Knowles-Gaylord Nelson stewardship 2000 program and a major land acquisitions program. (FE) | This bill reauthorizes the Warren Knowles-Gaylord Nelson Stewardship 2000 Program until 2030, makes changes to the land acquisition and property development and local assistance subprograms, and creates a separate major land acquisitions program. Reauthorization and changes to the stewardship program Current law authorizes the state to incur public debt for certain conservation activities under the stewardship program, which is administered by the Department of Natural Resources. The state may incur this debt to acquire land for the state for conservation purposes and for property development activities and may award grants or state aid to certain local governmental units and nonprofit conservation organizations (NCOs) to acquire and develop land for these purposes. Current law establishes the amounts that DNR may obligate in each fiscal year through fiscal year 2025-26 for expenditure under each of five subprograms of the stewardship program. The bill reauthorizes the stewardship program until fiscal year 2029-30. Under the stewardship subprogram for land acquisition, the bill continues to require that $1,000,000 be set aside to be obligated only for DNR land acquisition in each fiscal year. This equals the amount that current law requires to be set aside to be obligated only for DNR to acquire land for the Ice Age Trail. The bill reduces from $7,000,000 to $2,000,000 the amount to be set aside to be obligated for grants to NCOs to acquire and develop property for certain conservation purposes. Under current law, in the stewardship program the term XobligateY means to encumber or otherwise commit or to expend without having previously encumbered or otherwise committed, and is used with respect to limits on obligating or requirements to obligate certain amounts in the stewardship program. The bill specifies that XobligateY only refers to encumbering, otherwise committing, or expending public debt that the state is authorized to contract. In other words, XobligateY does not refer to amounts that are not the result of bonding. Under current law, DNR may obligate moneys for local assistance under the subprogram for property development and local assistance only for grant programs for urban green space, local parks, acquisition of property development rights, and urban rivers. Current law requires that such a grant may only be for up to 50 percent of the acquisition costs or development costs of a project. Under the bill, for such grants awarded to a governmental unit, no more than 30 percent of the remaining costs may be paid with funding provided from grants or in-kind contributions. Under current law, these grant programs define Xgovernmental unitY to include a city, village, town, county, or the Kickapoo reserve management board and, for urban green space grants, to also include a lake sanitary district or public inland lake protection and rehabilitation district. The bill also provides that if a governmental unit applies for such a grant after closing on the acquisition of the land in question, the grant may only be for up to 40 percent of the acquisition costs. The bill requires DNR to prioritize projects under any subprogram that involves property development over those that involve land acquisition. The bill eliminates a current law restriction providing that, of the amount set aside for DNR land acquisition and county forest grants under the stewardship program in a given fiscal year, not more than one-third may be obligated for the purpose of DNR land acquisition. The bill also eliminates a current law restriction providing that, of all of the available stewardship program bonding authority in a fiscal year, not more than 20 percent may be obligated for the acquisition of parcels of lands that are less than 10 acres in size. The bill adds a restriction that DNR may not obligate stewardship moneys for a land acquisition project that exceeds $1,000,000. For such projects, the bill creates a new, separate major land acquisitions program. Under the bill, in addition to obligating stewardship moneys to provide grants to NCOs for the acquisition of land for certain conservation purposes, DNR may obligate moneys to provide grants to NCOs to develop, manage, preserve, restore, and maintain wildlife habitat on public lands to benefit game species and other wildlife. The bill requires DNR to prioritize wildlife habitat grants over land acquisition grants under the NCO grant program. Under current law, if in a given fiscal year the amount DNR obligates to provide land acquisition grants to NCOs is less than the amount set aside for that purpose in that fiscal year, DNR may obligate the unobligated amount in the next fiscal year but only for the purpose of awarding a grant to a county for the acquisition of land for a county forest. Under this bill, such unobligated amounts may only be obligated for local assistance grants. Under current law, if DNR does not obligate an amount authorized to be obligated for a subprogram in a fiscal year, DNR may not adjust the annual bonding authority for that subprogram by raising the annual bonding authority for the next fiscal year. Under current law, portions of the unobligated amounts for the land acquisition, property development and local assistance, and recreational boating aids subprograms from various fiscal years from 2011-12 to 2025-26 are obligated for specific purposes. One such provision under current law requires DNR to obligate all unobligated amounts from those subprograms from any fiscal year, including for drilling new wells, facility maintenance, upgrades, and renovations, and construction of new buildings. The bill limits this obligation to only those unobligated amounts for those subprograms from the fiscal years 2021-22 and 2022-23, and specifies that $2,500,000 of that unobligated amount must be obligated for projects at the Les Voigt State Fish Hatchery and the Brule State Fish Hatchery, including drilling new wells, facility maintenance, upgrades and renovations, and construction of new buildings. Major land acquisitions program The bill creates a new major land acquisitions program, under which the bill authorizes DNR to use or obligate moneys to acquire land for the state for conservation purposes or to award grants to NCOs or local governments to acquire land for those purposes if two conditions are met: 1) the project or grant exceeds $1,000,000; and 2) the project or grant is enumerated through legislation. To request enumeration of such projects, the bill requires DNR annually to, no later than January 15, submit to the joint committee on finance and to the appropriate legislative standing committees a list of all proposed major land acquisitions for the subsequent fiscal biennium, including estimated purchase prices, requested state funding sources, and nonstate sources of funding, such as federal grants or donations. The bill authorizes DNR to submit a list of proposed major land acquisitions not listed under the prior proposed list at any time during a fiscal biennium. Under the bill, the legislature may enumerate projects from either list through legislation. For further information see the state and local fiscal estimate, which will be printed as an appendix to this bill. | In Committee |
| SB316 | The Warren Knowles-Gaylord Nelson stewardship 2000 program and a major land acquisitions program. (FE) | This bill reauthorizes the Warren Knowles-Gaylord Nelson Stewardship 2000 Program until 2030, makes changes to the land acquisition and property LRB-3557/1 EHS:skw&emw 2025 - 2026 Legislature SENATE BILL 316 development and local assistance subprograms, and creates a separate major land acquisitions program. Reauthorization and changes to the stewardship program Current law authorizes the state to incur public debt for certain conservation activities under the stewardship program, which is administered by the Department of Natural Resources. The state may incur this debt to acquire land for the state for conservation purposes and for property development activities and may award grants or state aid to certain local governmental units and nonprofit conservation organizations (NCOs) to acquire and develop land for these purposes. Current law establishes the amounts that DNR may obligate in each fiscal year through fiscal year 2025-26 for expenditure under each of five subprograms of the stewardship program. The bill reauthorizes the stewardship program until fiscal year 2029-30. Under the stewardship subprogram for land acquisition, the bill continues to require that $1,000,000 be set aside to be obligated only for DNR land acquisition in each fiscal year. This equals the amount that current law requires to be set aside to be obligated only for DNR to acquire land for the Ice Age Trail. The bill reduces from $7,000,000 to $2,000,000 the amount to be set aside to be obligated for grants to NCOs to acquire and develop property for certain conservation purposes. Under current law, in the stewardship program the term XobligateY means to encumber or otherwise commit or to expend without having previously encumbered or otherwise committed, and is used with respect to limits on obligating or requirements to obligate certain amounts in the stewardship program. The bill specifies that XobligateY only refers to encumbering, otherwise committing, or expending public debt that the state is authorized to contract. In other words, XobligateY does not refer to amounts that are not the result of bonding. Under current law, DNR may obligate moneys for local assistance under the subprogram for property development and local assistance only for grant programs for urban green space, local parks, acquisition of property development rights, and urban rivers. Current law requires that such a grant may only be for up to 50 percent of the acquisition costs or development costs of a project. Under the bill, for such grants awarded to a governmental unit, no more than 30 percent of the remaining costs may be paid with funding provided from grants or in-kind contributions. Under current law, these grant programs define Xgovernmental unitY to include a city, village, town, county, or the Kickapoo reserve management board and, for urban green space grants, to also include a lake sanitary district or public inland lake protection and rehabilitation district. The bill also provides that if a governmental unit applies for such a grant after closing on the acquisition of the land in question, the grant may only be for up to 40 percent of the acquisition costs. The bill requires DNR to prioritize projects under any subprogram that involves property development over those that involve land acquisition. The bill eliminates a current law restriction providing that, of the amount set aside for DNR land acquisition and county forest grants under the stewardship program in a given fiscal year, not more than one-third may be obligated for the purpose of DNR land acquisition. The bill also eliminates a current law restriction LRB-3557/1 EHS:skw&emw 2025 - 2026 Legislature SENATE BILL 316 providing that, of all of the available stewardship program bonding authority in a fiscal year, not more than 20 percent may be obligated for the acquisition of parcels of lands that are less than 10 acres in size. The bill adds a restriction that DNR may not obligate stewardship moneys for a land acquisition project that exceeds $1,000,000. For such projects, the bill creates a new, separate major land acquisitions program. Under the bill, in addition to obligating stewardship moneys to provide grants to NCOs for the acquisition of land for certain conservation purposes, DNR may obligate moneys to provide grants to NCOs to develop, manage, preserve, restore, and maintain wildlife habitat on public lands to benefit game species and other wildlife. The bill requires DNR to prioritize wildlife habitat grants over land acquisition grants under the NCO grant program. Under current law, if in a given fiscal year the amount DNR obligates to provide land acquisition grants to NCOs is less than the amount set aside for that purpose in that fiscal year, DNR may obligate the unobligated amount in the next fiscal year but only for the purpose of awarding a grant to a county for the acquisition of land for a county forest. Under this bill, such unobligated amounts may only be obligated for local assistance grants. Under current law, if DNR does not obligate an amount authorized to be obligated for a subprogram in a fiscal year, DNR may not adjust the annual bonding authority for that subprogram by raising the annual bonding authority for the next fiscal year. Under current law, portions of the unobligated amounts for the land acquisition, property development and local assistance, and recreational boating aids subprograms from various fiscal years from 2011-12 to 2025-26 are obligated for specific purposes. One such provision under current law requires DNR to obligate all unobligated amounts from those subprograms from any fiscal year, including for drilling new wells, facility maintenance, upgrades, and renovations, and construction of new buildings. The bill limits this obligation to only those unobligated amounts for those subprograms from the fiscal years 2021-22 and 2022-23, and specifies that $2,500,000 of that unobligated amount must be obligated for projects at the Les Voigt State Fish Hatchery and the Brule State Fish Hatchery, including drilling new wells, facility maintenance, upgrades and renovations, and construction of new buildings. Major land acquisitions program The bill creates a new major land acquisitions program, under which the bill authorizes DNR to use or obligate moneys to acquire land for the state for conservation purposes or to award grants to NCOs or local governments to acquire land for those purposes if two conditions are met: 1) the project or grant exceeds $1,000,000; and 2) the project or grant is enumerated through legislation. To request enumeration of such projects, the bill requires DNR annually to, no later than January 15, submit to the joint committee on finance and to the appropriate legislative standing committees a list of all proposed major land acquisitions for the subsequent fiscal biennium, including estimated purchase prices, requested state funding sources, and nonstate sources of funding, such as federal grants or donations. The bill authorizes DNR to submit a list of proposed major land LRB-3557/1 EHS:skw&emw 2025 - 2026 Legislature SENATE BILL 316 acquisitions not listed under the prior proposed list at any time during a fiscal biennium. Under the bill, the legislature may enumerate projects from either list through legislation. For further information see the state and local fiscal estimate, which will be printed as an appendix to this bill. | In Committee |
| AB284 | Enumeration of projects in the Authorized State Building Program, modifications to building program project budgets, selection of project architects and engineers, single prime contracting, agency cooperation with energy conservation contractors, timeline for claims before the Claims Board, and making a transfer to the state building trust fund. (FE) | PROJECT ENUMERATIONS OF IN THE AUTHORIZED STATE BUILDING PROGRAM Under current law, the Building Commission may authorize the design and construction of any building, structure, or facility costing in excess of $2,000,000, only if that project is enumerated in the Authorized State Building Program, which appears in each biennial budget passed by the legislature. This bill eliminates that enumeration requirement for the design phase of a project and provides that the construction of any building, structure, or facility may not be enumerated in the authorized state building program unless the building commission determines that at least 50 percent of the project[s design phase has already been completed. REPORTS CONCERNING MODIFICATIONS TO BUILDING PROGRAM PROJECTS Under current law, the Building Commission has the authority to authorize limited changes in the program or budget of a building program project if the commission determines that unanticipated program conditions or bidding conditions require the change to effectively and economically construct the project. This bill requires that the Department of Administration submit a quarterly report to the Joint Committee on Finance and each voting member of the Building Commission that identifies each project for which the Building Commission has approved a budget increase and that identifies each project enumerated in the state building program for which DOA estimates a budget increase will be necessary for project completion, including a description of the reasons for the project budget shortfall. SELECTION OF PROJECT ARCHITECTS AND ENGINEERS Under current law, the secretary of administration is required to establish a committee for each construction project under DOA[s supervision, except certain emergency projects, for the purpose of selecting an architect or engineer for the project. If the estimated cost of a construction project is $7,400,000 or more, the selection committee must use a request-for-proposal process established by DOA to select an architect or engineer for the project based on qualifications. The bill raises that threshold to $15,000,000. SINGLE PRIME CONTRACTING The bill creates a new exception to single prime contracting for high-dollar building projects. Single prime contracting is a process in which the state contracts only with a general prime contractor who then must contract with subcontractors. Under current law, whenever the Building Commission determines that the use of innovative types of design and construction processes will make better use of the resources and technology available in the building industry, the commission may waive certain requirements related to single prime contracting, if the action is in the best interest of the state and is approved by the commission. Under the bill, for any project costing $200,000,000 or more, at the request of the agency for which the project is constructed, the Building Commission is required to waive certain single prime contracting requirements for the project, as requested by the agency. CERTAIN PROJECT BIDDING PROCEDURES Under the bill, at any time more than two days prior to the end of the period during which bids may be submitted for a building project, a bidder or potential bidder may submit a question to DOA concerning the project. Additionally, the bill provides that DOA may issue addenda at any time during the bidding period to modify or clarify the drawings and specifications for the project being bid or to extend the bidding period. COOPERATION WITH ENERGY CONSERVATION CONTRACTORS Current law authorizes DOA to contract with qualified contractors for the performance of energy conservation audits at state buildings, structures, and facilities and for the performance of construction work at a state building, structure, or facility for the purpose of realizing potential savings of future energy costs identified in an energy conservation audit. The bill requires DOA and the Board of Regents of the University of Wisconsin System to collaborate with energy service companies to identify and execute pilot projects using financing provided by the companies to upgrade facilities, reduce deferred maintenance, and increase sustainability. UTILITIES COSTS The bill provides that each state contract for construction work must state which party to the contract is responsible for paying project utility service connection charges and which party is responsible for paying for costs related to the consumption of utility services at the project site. ACTIONS AGAINST THE STATE RELATED TO CERTAIN CONTRACT CLAIMS Under current law, the Claims Board is required to receive, investigate, and make recommendations on all claims against the state of $10 or more that are referred to the board by DOA. The board is required to report its findings and recommendations on all claims referred to the board to the legislature. The board may deny a claim, directly pay a claim of up to $10,000, or recommend a payment in excess of $10,000 to the legislature. If the board concludes that a claim should be paid by the state and the board does not or may not directly pay the claim, current law requires the board to cause a bill to be drafted covering its recommendations. A claimant may commence a lawsuit against the state upon the refusal of the legislature to pass a bill allowing a claim. The bill creates a timeline for the board to hear and make a final determination upon certain claims related to contracts and, in addition to current law, allows claimants to bring actions against the state related to certain contract claims if certain conditions are met. Under the bill, any claim referred to the board that relates to a contract with the Department of Transportation for transportation infrastructure improvement or that relates to a contract with DOA or the Board of Regents of the University of Wisconsin System that is awarded under current law for construction projects must be heard by the board, and the board must make a final determination on the claim, within six months from the day that the claim was referred to the board. If the board concludes that the facts of the claim would be more properly adjudicated in a court of law or if the board fails to make a final determination on the claim within six months from the date that the claim was referred to the board, the bill allows the claimant to commence an action against the state seeking judgment on the claim as provided under current law. TRANSFER TO THE BUILDING TRUST FUND The bill transfers $32,000,000 from the general fund to the building trust fund in fiscal year 2024-25. For further information see the state fiscal estimate, which will be printed as an appendix to this bill. | In Committee |
| SB241 | Tax incremental financing districts containing qualified data centers. (FE) | Under current law, there is a sales and use tax exemption for certain property and items used to construct, operate, or renovate a qualified data center, as certified by the Wisconsin Economic Development Corporation. Also under current law, the equalized value of the taxable property of a new or amended tax incremental district (TID) plus the value increment of all existing TIDs in a city or village may not exceed 12 percent of the total equalized value of taxable property in the city or village. Under this bill, the 12 percent rule does not apply to a TID that contains within its boundaries a qualified data center certified by WEDC if all of the project costs of the TID are related to the qualified data center. For further information see the state and local fiscal estimate, which will be printed as an appendix to this bill. | In Committee |
| SJR2 | Requiring photographic identification to vote in any election (second consideration). | To create section 1m of article III of the constitution; Relating to: requiring photographic identification to vote in any election (second consideration). | Signed/Enacted/Adopted |
| AJR4 | Honoring the life and public service of Justice David T. Prosser Jr. | Relating to: honoring the life and public service of Justice David T. Prosser Jr. | Signed/Enacted/Adopted |
| AB228 | Tax incremental financing districts containing qualified data centers. (FE) | Under current law, there is a sales and use tax exemption for certain property and items used to construct, operate, or renovate a qualified data center, as certified by the Wisconsin Economic Development Corporation. Also under current law, the equalized value of the taxable property of a new or amended tax incremental district (TID) plus the value increment of all existing TIDs in a city or village may not exceed 12 percent of the total equalized value of taxable property in the city or village. Under this bill, the 12 percent rule does not apply to a TID that contains within its boundaries a qualified data center certified by WEDC if all of the project costs of the TID are related to the qualified data center. For further information see the state and local fiscal estimate, which will be printed as an appendix to this bill. | In Committee |
| AB1 | Changes to the educational assessment program and the school and school district accountability report. (FE) | Under current law, the Department of Public Instruction is required to annually publish a school and school district accountability report, commonly known as school and school district report cards, for the previous school year. To measure school performance and school district improvement for purposes of the report cards, particularly measures related to pupil achievement in reading and math, DPI uses data derived from pupil performance on assessments administered in the previous school year, including assessments commonly referred to as the Wisconsin Student Assessment System, which includes the Wisconsin Forward Exam, PreACT, the ACT with Writing, and Dynamic Learning Maps. Under the bill, beginning with report cards published for the school year in which the bill becomes law, for the index system to identify school and school district performance and improvement, also known as the accountability rating categories, DPI must use the same cut scores, score ranges, and corresponding qualitative descriptions that DPI used for report cards published in the 2019-20 school year. In addition, beginning with the WSAS administered in the school year in which the bill becomes law, DPI must do the following: 1. For the Wisconsin Forward exam in English Language Arts and Mathematics, align cut scores, score ranges, and pupil performance categories to the cut scores, score ranges, and pupil performance categories set by the National Assessment of Educational Progress. 2. For the PreACT and ACT with Writing in English, Reading, and Mathematics, use the same cut scores, score ranges, and pupil performance categories that DPI used for the same assessments administered in the 2021-22 school year. The bill specifically requires DPI to use the terms “below basic,” “basic,” “proficient,” and “advanced” for pupil performance categories on these assessments. For further information see the state fiscal estimate, which will be printed as an appendix to this bill. | Vetoed |
| SB26 | Technical colleges’ lease of their facilities to others. (FE) | This bill allows a technical college to lease its facilities to others for the operation of a child care center. Current law allows a technical college to rent to others property not needed for school purposes. Before July 1, 1999, a technical college, with the approval of the Technical College System Board, could also lease its facilities to others for school purposes, but this is prohibited after June 30, 1999. The bill creates an exception to this prohibition, allowing a technical college, with the approval of the TCS Board, to lease its facilities to others for the operation of a child care center. For further information see the local fiscal estimate, which will be printed as an appendix to this bill. | In Committee |
| AB21 | Technical colleges’ lease of their facilities to others. (FE) | This bill allows a technical college to lease its facilities to others for the operation of a child care center. Current law allows a technical college to rent to others property not needed for school purposes. Before July 1, 1999, a technical college, with the approval of the Technical College System Board, could also lease its facilities to others for school purposes, but this is prohibited after June 30, 1999. The bill creates an exception to this prohibition, allowing a technical college, with the approval of the TCS Board, to lease its facilities to others for the operation of a child care center. For further information see the local fiscal estimate, which will be printed as an appendix to this bill. | In Committee |
| SB18 | Changes to the educational assessment program and the school and school district accountability report. (FE) | Under current law, the Department of Public Instruction is required to annually publish a school and school district accountability report, commonly known as school and school district report cards, for the previous school year. To measure school performance and school district improvement for purposes of the report cards, particularly measures related to pupil achievement in reading and math, DPI uses data derived from pupil performance on assessments administered in the previous school year, including assessments commonly referred to as the Wisconsin Student Assessment System, which includes the Wisconsin Forward Exam, PreACT, the ACT with Writing, and Dynamic Learning Maps. Under the bill, beginning with report cards published for the school year in which the bill becomes law, for the index system to identify school and school district performance and improvement, also known as the accountability rating categories, DPI must use the same cut scores, score ranges, and corresponding qualitative descriptions that DPI used for report cards published in the 2019-20 LRB-0976/4 FFK:cjs&skw 2025 - 2026 Legislature SENATE BILL 18 school year. In addition, beginning with the WSAS administered in the school year in which the bill becomes law, DPI must do the following: 1. For the Wisconsin Forward exam in English Language Arts and Mathematics, align cut scores, score ranges, and pupil performance categories to the cut scores, score ranges, and pupil performance categories set by the National Assessment of Educational Progress. 2. For the PreACT and ACT with Writing in English, Reading, and Mathematics, use the same cut scores, score ranges, and pupil performance categories that DPI used for the same assessments administered in the 2021-22 school year. The bill specifically requires DPI to use the terms Xbelow basic,Y Xbasic,Y Xproficient,Y and XadvancedY for pupil performance categories on these assessments. For further information see the state fiscal estimate, which will be printed as an appendix to this bill. | In Committee |
| SJR9 | Honoring the life and public service of Justice David T. Prosser Jr. | Relating to: honoring the life and public service of Justice David T. Prosser Jr. | In Committee |
| AJR1 | Requiring photographic identification to vote in any election (second consideration). | To create section 1m of article III of the constitution; Relating to: requiring photographic identification to vote in any election (second consideration). | In Committee |
| Bill | Bill Name | Motion | Vote Date | Vote |
|---|---|---|---|---|
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 24 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 23 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 22 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 21 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 20 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 19 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 18 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 17 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 16 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 15 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 14 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 13 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 12 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 11 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 10 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 9 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 8 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 7 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 6 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 5 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 4 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 3 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 2 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| AB50 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Assembly Amendment 1 to Assembly Substitute Amendment 2 laid on table | 07/02/2025 | Yea |
| SB45 | State finances and appropriations, constituting the executive budget act of the 2025 legislature. (FE) | Assembly: Read a third time and concurred in | 07/02/2025 | Yea |
| AB17 | Creating an employee ownership conversion costs tax credit, a deduction for capital gains from the transfer of a business to employee ownership, and an employee ownership education and outreach program. (FE) | Assembly: Read a third time and passed | 06/24/2025 | Yea |
| AB63 | Financing the operating costs and certain out-of-state projects of nonprofit institutions and compensation of employees of the Wisconsin Health and Educational Facilities Authority. (FE) | Assembly: Read a third time and passed | 06/24/2025 | Yea |
| SB108 | Sharing minors’ safety plans. (FE) | Assembly: Assembly Amendment 1 laid on table | 06/24/2025 | Yea |
| SB108 | Sharing minors’ safety plans. (FE) | Assembly: Assembly Substitute Amendment 1 laid on table | 06/24/2025 | Yea |
| SB106 | Psychiatric residential treatment facilities, providing an exemption from emergency rule procedures, and granting rule-making authority. | Assembly: Assembly Amendment 1 laid on table | 06/24/2025 | Yea |
| SB106 | Psychiatric residential treatment facilities, providing an exemption from emergency rule procedures, and granting rule-making authority. | Assembly: Assembly Substitute Amendment 1 laid on table | 06/24/2025 | Yea |
| SB283 | Public protective services hearing protection assistance. (FE) | Assembly: Assembly Amendment 1 laid on table | 06/24/2025 | Yea |
| SB283 | Public protective services hearing protection assistance. (FE) | Assembly: Assembly Substitute Amendment 1 laid on table | 06/24/2025 | Yea |
| AB279 | Talent recruitment grants. (FE) | Assembly: Assembly Amendment 1 laid on table | 06/24/2025 | Yea |
| AB279 | Talent recruitment grants. (FE) | Assembly: Assembly Substitute Amendment 1 laid on table | 06/24/2025 | Yea |
| AJR50 | Recognizing the United States Army’s 250th birthday. | Assembly: Adopted | 06/18/2025 | Yea |
| AB269 | Delivery network couriers and transportation network drivers, Department of Financial Institutions’ approval to offer portable benefit accounts, providing for insurance coverage, modifying administrative rules related to accident and sickness insurance, and granting rule-making authority. (FE) | Assembly: Read a third time and passed | 06/18/2025 | Yea |
| SB24 | Limitations on the total value of taxable property that may be included in, and the lifespan of, a tax incremental financing district created in the city of Middleton. (FE) | Assembly: Read a third time and concurred in | 05/13/2025 | Yea |
| AB23 | Establishment of a Palliative Care Council. (FE) | Assembly: Read a third time and passed | 05/13/2025 | Yea |
| AB43 | Permitting pharmacists to prescribe certain contraceptives, extending the time limit for emergency rule procedures, providing an exemption from emergency rule procedures, granting rule-making authority, and providing a penalty. (FE) | Assembly: Read a third time and passed | 05/13/2025 | Yea |
| AB137 | Maximum life and allocation period for Tax Incremental District Number 9 in the village of DeForest and the total value of taxable property that may be included in tax incremental financing districts created in the village of DeForest. (FE) | Assembly: Read a third time and passed | 05/13/2025 | Yea |
| AB140 | Limitations on the total value of taxable property that may be included in a tax incremental financing district created in the city of Port Washington. (FE) | Assembly: Read a third time and passed | 05/13/2025 | Yea |
| AB73 | Statutory recognition of specialized treatment court and commercial court dockets. | Assembly: Read a third time and passed | 04/22/2025 | Yea |
| AB164 | Various changes to the unemployment insurance law and federal Reemployment Services and Eligibility Assessment grants. (FE) | Assembly: Read a third time and passed | 04/22/2025 | Yea |
| AB165 | Local guaranteed income programs. | Assembly: Read a third time and passed | 04/22/2025 | Yea |
| AB166 | Academic and career planning services provided to pupils and requiring the reporting of certain data on college student costs and outcomes. (FE) | Assembly: Read a third time and passed | 04/22/2025 | Yea |
| AB162 | Workforce metrics. (FE) | Assembly: Read a third time and passed | 04/22/2025 | Yea |
| AB168 | Various changes to the unemployment insurance law. (FE) | Assembly: Read a third time and passed | 04/22/2025 | Yea |
| AB169 | Various changes to the unemployment insurance law. (FE) | Assembly: Read a third time and passed | 04/22/2025 | Yea |
| AB167 | Various changes to the unemployment insurance law and requiring approval by the Joint Committee on Finance of certain federally authorized unemployment benefits. (FE) | Assembly: Read a third time and passed | 04/22/2025 | Yea |
| AB102 | Designating University of Wisconsin and technical college sports and athletic teams based on the sex of the participants. | Assembly: Read a third time and passed | 03/20/2025 | Yea |
| AB100 | Designating athletic sports and teams operated or sponsored by public schools or private schools participating in a parental choice program based on the sex of the participants. | Assembly: Read a third time and passed | 03/20/2025 | Yea |
| AB103 | School board policies related to changing a pupil’s legal name and pronouns. | Assembly: Read a third time and passed | 03/20/2025 | Yea |
| AB104 | Prohibiting gender transition medical intervention for individuals under 18 years of age. | Assembly: Read a third time and passed | 03/20/2025 | Yea |
| AB105 | The distribution of certain material on the Internet. | Assembly: Read a third time and passed | 03/20/2025 | Yea |
| AB24 | County sheriff assistance with certain federal immigration functions. (FE) | Assembly: Read a third time and passed | 03/18/2025 | Yea |
| AB96 | Ratification of the agreement negotiated between the Board of Regents of the University of Wisconsin System and the Wisconsin State Building Trades Negotiating Committee, for the 2024-25 fiscal year, covering employees in the building trades crafts collective bargaining unit, and authorizing an expenditure of funds. (FE) | Assembly: Read a third time and passed | 03/18/2025 | Yea |
| AB94 | Ratification of the agreement negotiated between the State of Wisconsin and the Wisconsin State Building Trades Negotiating Committee, for the 2024-25 fiscal year, covering employees in the building trades crafts collective bargaining unit, and authorizing an expenditure of funds. (FE) | Assembly: Read a third time and passed | 03/18/2025 | Yea |
| AB95 | Ratification of the agreement negotiated between the University of Wisconsin-Madison and the Wisconsin State Building Trades Negotiating Committee, for the 2024-25 fiscal year, covering employees in the building trades crafts collective bargaining unit, and authorizing an expenditure of funds. (FE) | Assembly: Read a third time and passed | 03/18/2025 | Yea |
| AB14 | The suspension of a rule of the Elections Commission. | Assembly: Referred to Campaigns and Elections | 03/13/2025 | Yea |
| AB15 | The suspension of a rule of the Elections Commission. | Assembly: Referred to Campaigns and Elections | 03/13/2025 | Yea |
| AB16 | Repealing an administrative rule of the Department of Natural Resources related to the possession of firearms. | Assembly: Referred to Environment | 03/13/2025 | Yea |
| AB13 | The suspension of a rule of the Elections Commission. | Assembly: Referred to Campaigns and Elections | 03/13/2025 | Yea |
| AB66 | Dismissing or amending certain criminal charges and deferred prosecution agreements for certain crimes. | Assembly: Read a third time and passed | 03/13/2025 | Yea |
| AB66 | Dismissing or amending certain criminal charges and deferred prosecution agreements for certain crimes. | Assembly: Decision of the Chair upheld | 03/13/2025 | Yea |
| AB75 | Department of Justice collection and reporting of certain criminal case data. (FE) | Assembly: Read a third time and passed | 03/13/2025 | Yea |
| AB85 | Recommendation to revoke extended supervision, parole, or probation if a person is charged with a crime. (FE) | Assembly: Read a third time and passed | 03/13/2025 | Yea |
| AB85 | Recommendation to revoke extended supervision, parole, or probation if a person is charged with a crime. (FE) | Assembly: Assembly Substitute Amendment 1 laid on table | 03/13/2025 | Yea |
| AB89 | Theft crimes and providing a penalty. (FE) | Assembly: Read a third time and passed | 03/13/2025 | Yea |
| AB91 | The requirement that first class cities and first class city school districts place school resource officers in schools. (FE) | Assembly: Read a third time and passed | 03/13/2025 | Yea |
| AB91 | The requirement that first class cities and first class city school districts place school resource officers in schools. (FE) | Assembly: Decision of the Chair upheld | 03/13/2025 | Yea |
| AB87 | Restitution orders following a conviction for human trafficking and restoration of the right to vote to a person barred from voting as a result of a felony conviction. (FE) | Assembly: Read a third time and passed | 03/13/2025 | Yea |
| AB1 | Changes to the educational assessment program and the school and school district accountability report. (FE) | Assembly: Read a third time and passed | 02/19/2025 | Yea |
| AB5 | Requiring school boards to make textbooks, curricula, and instructional materials available for inspection by school district residents. | Assembly: Read a third time and passed | 02/19/2025 | Yea |
| AB3 | Incorporating cursive writing into the state model English language arts standards and requiring cursive writing in elementary grades. (FE) | Assembly: Read a third time and passed | 02/19/2025 | Yea |
| AB4 | Required instruction in civics in the elementary and high school grades, high school graduation requirements, and private school educational program criteria. (FE) | Assembly: Read a third time and passed | 02/19/2025 | Yea |
| AB4 | Required instruction in civics in the elementary and high school grades, high school graduation requirements, and private school educational program criteria. (FE) | Assembly: Decision of the Chair upheld | 02/19/2025 | Yea |
| AB2 | Requiring school boards to adopt policies to prohibit the use of wireless communication devices during instructional time. | Assembly: Read a third time and passed | 02/19/2025 | Yea |
| AB6 | Requiring a school board to spend at least 70 percent of its operating expenditures on direct classroom expenditures and annual pay increases for school administrators. (FE) | Assembly: Read a third time and passed | 02/19/2025 | Yea |
| AB6 | Requiring a school board to spend at least 70 percent of its operating expenditures on direct classroom expenditures and annual pay increases for school administrators. (FE) | Assembly: Decision of the Chair upheld | 02/19/2025 | Yea |
| SJR2 | Requiring photographic identification to vote in any election (second consideration). | Assembly: Read a third time and concurred in | 01/14/2025 | Yea |
| AR1 | Notifying the senate and the governor that the 2025-2026 assembly is organized. | Assembly: Adopted | 01/06/2025 | Yea |
| SJR1 | The session schedule for the 2025-2026 biennial session period. | Assembly: Concurred in | 01/06/2025 | Yea |
| AR2 | Establishing the assembly committee structure and names for the 2025-2026 legislative session. | Assembly: Adopted | 01/06/2025 | Yea |
| State | District | Chamber | Party | Status | Start Date | End Date |
|---|---|---|---|---|---|---|
| WI | Wisconsin Assembly District 37 | Assembly | Republican | In Office | 01/06/2025 | |
| WI | Wisconsin Assembly District 39 | Assembly | Republican | Out of Office | 01/07/2013 | 01/07/2025 |